Arizona IT service contract template
View and compare the Free version and the Pro version.
Help Center
Need to learn how to convert downloaded contract DOCX files to PDF or add electronic signatures? Please visit our Help Center for detailed guidance.
How Arizona IT service contract Differ from Other States
-
Arizona requires IT service providers to comply with specific state data privacy and breach notification laws not present elsewhere.
-
The contract must consider Arizona’s strict non-compete and non-solicitation enforcement standards that can differ from other states.
-
Arizona recognizes electronic signatures and records under state law, impacting contract execution more distinctively than in some states.
Frequently Asked Questions (FAQ)
-
Q: Is a written IT service contract required for Arizona businesses?
A: While not legally required, a written contract is highly recommended to clarify the scope, payment, and protect both parties.
-
Q: Do Arizona IT contracts need to address data privacy specifically?
A: Yes, Arizona law mandates compliance with state-specific data privacy and breach notification standards in IT service agreements.
-
Q: Are electronic signatures valid on Arizona IT service contracts?
A: Yes, electronic signatures are recognized and legally valid for IT service contracts under Arizona law.
HTML Code Preview
Arizona IT Service Contract
Effective Date: [Date]
1. Parties
Service Provider:
- Name: [Service Provider Name]
- Business Form: [LLC, Corporation, etc.]
- Arizona Business Registration Number: [Registration Number]
- Arizona Commercial Address: [Street Address, City, State, Zip Code]
- Contact Person: [Contact Person Name]
- Email: [Email Address]
- Phone: [Phone Number]
Client:
- Name: [Client Name]
- Business Form: [LLC, Corporation, etc.]
- Arizona Business Registration Number: [Registration Number] (if applicable)
- Arizona Commercial Address: [Street Address, City, State, Zip Code]
- Contact Person: [Contact Person Name]
- Email: [Email Address]
- Phone: [Phone Number]
2. Scope of Services
Option A: Managed Services
Comprehensive IT management including network administration, cloud solutions, cybersecurity protection, hardware maintenance, software development, systems integration, data backup/recovery, technical support (onsite or remote), and service desk operations. Details outlined in Exhibit A.
Option B: Ad Hoc Support
IT support provided on an as-needed basis. Services include [Specify Services, e.g., server maintenance, virus removal, hardware repair]. Rate and availability are detailed in Exhibit B.
Option C: Turnkey Solutions
Complete IT solutions provided for specific projects. Includes [Specify Project Details, e.g., new network setup, software deployment]. Project specifications are outlined in Exhibit C.
3. Deliverables
Item 1: [Description of Deliverable, e.g., Network Infrastructure Diagram]
- Technical Specifications: [Specify Technical Details]
- Functional Specifications: [Specify Functional Details]
- Standard of Performance: [Specify Performance Standard]
- Compliance: Complies with industry protocols and standards, including those relevant to Arizona's Critical Infrastructure Protection Act and applicable privacy/security frameworks (such as HIPAA and GLBA if serving relevant industries).
Item 2: [Description of Deliverable, e.g., Security Audit Report]
- Technical Specifications: [Specify Technical Details]
- Functional Specifications: [Specify Functional Details]
- Standard of Performance: [Specify Performance Standard]
- Compliance: Complies with industry protocols and standards, including those relevant to Arizona's Critical Infrastructure Protection Act and applicable privacy/security frameworks (such as HIPAA and GLBA if serving relevant industries).
4. Service Level Agreement (SLA)
System Uptime: [Percentage]% uptime commitment during Arizona business hours (8 AM - 5 PM MST).
Response Time: Initial response within [Number] hours for critical issues.
Resolution Time: Resolution within [Number] hours for critical issues.
Escalation Procedures: Defined in Exhibit D. Measurable service metrics outlined in Exhibit E.
5. Project Timeline and Milestones
Project Start Date: [Date]
Milestone 1: [Description of Milestone] - Due Date: [Date]
Milestone 2: [Description of Milestone] - Due Date: [Date]
Project Completion Date: [Date]
Completion Criteria: [Specify Completion Criteria]. Client feedback/acceptance process outlined in Exhibit F.
6. Client Cooperation
- Responsibility 1: Timely system access provided by [Date].
- Responsibility 2: Provision of necessary documentation by [Date].
- Responsibility 3: Provision of data, hardware, or third-party software licenses by [Date].
- Deadlines: All deadlines are crucial for project success.
7. Service Site
Option A: Arizona-Based
Services primarily provided from a location within Arizona.
Option B: Remote
Services provided remotely.
Option C: Hybrid
Services provided both in Arizona and remotely. Travel to Arizona client locations reimbursed at [Dollar Amount] per mile, compliant with Arizona business expense rules.
8. Payment Terms
Total Price: [Dollar Amount]
Payment Schedule: [Specify Payment Schedule, e.g., monthly, quarterly]
Invoices: Itemized invoices conforming to Arizona business tax rules. Applicable Arizona transaction privilege tax or sales tax of [Percentage]% will be added.
Late Payment Penalties: Late payments subject to a [Percentage]% monthly interest charge, in accordance with Arizona law.
9. Intellectual Property (IP)
Option A: Work Made for Hire
All deliverables are considered "work made for hire" under Arizona law and owned by the Client.
Option B: Provider Ownership
Service Provider retains ownership of source code, developed software, and configuration files. Client receives a perpetual license to use the deliverables.
Licensing: [Specify Open-Source or Proprietary Licensing]. Client usage limitations are outlined in Exhibit G. Provider portfolio display rights subject to Client approval.
10. Confidentiality
Both parties shall protect proprietary code, business data, client/customer lists, and security-related information in accordance with the Arizona Uniform Trade Secrets Act. Post-termination obligations survive this agreement.
11. Data Protection and Cybersecurity
Minimum technical/security standards aligned with Arizona statutes. Incident notification within [Number] hours. Provider obligations to remediate security incidents outlined in Exhibit H. Client consent procedures for data access/storage are detailed in Exhibit I.
12. Quality Assurance
Routine maintenance and update cycles: [Specify Frequency]. Bug/defect correction timeframe: [Number] hours. Post-delivery support for [Number] months. Exclusions for issues caused by client changes or misuse. Documentation and handover processes are outlined in Exhibit J.
13. Change Management
Procedures for service modifications, scope changes, or technology shifts require mutual approval. Timeline and cost adjustments detailed in Exhibit K.
14. Force Majeure
Includes Arizona-specific events such as wildfires and utility outages. Notification, mitigation, and recovery obligations defined in Exhibit L.
15. Termination
Termination for Breach: Failure to meet SLAs or regulatory violations.
Termination for Convenience: Either party may terminate with [Number] days' written notice.
Mutual Agreement: Termination by mutual written agreement.
Cessation of Business in Arizona: In the event either party ceases operations in Arizona. Transition assistance, return or destruction of client data, and payment of outstanding fees detailed in Exhibit M.
16. Liability
Cap on damages: [Dollar Amount]. Exclusions for indirect damages unless due to security breaches. Indemnification for third-party IP disputes and data privacy failures. Compliance with Arizona's liability limitation statutes.
17. Dispute Resolution
Governing Law and Jurisdiction: Arizona. Negotiation and mediation process in line with Arizona court rules. Arbitration (if applicable) through [Arbitration Organization].
18. Compliance with Arizona Law
Compliance with Arizona-specific IT regulations, such as state data breach notification laws, contractor registration (if serving government clients), DEIE (Digital Electronic Information Exchange) rules, and statutes on consumer IT services. Adherence to statutes on e-signature validity under Arizona law, and local licensing/insurance mandates.
IN WITNESS WHEREOF, the parties have executed this Agreement as of the Effective Date.
Service Provider:
[Signature]
[Printed Name]
Client:
[Signature]
[Printed Name]
Exhibits:
- Exhibit A: Scope of Services - Managed Services Details
- Exhibit B: Scope of Services - Ad Hoc Support Rates
- Exhibit C: Scope of Services - Turnkey Solutions Specifications
- Exhibit D: Service Level Agreement - Escalation Procedures
- Exhibit E: Service Level Agreement - Service Metrics
- Exhibit F: Project Timeline and Milestones - Client Feedback/Acceptance Process
- Exhibit G: Intellectual Property - Client Usage Limitations
- Exhibit H: Data Protection and Cybersecurity - Security Incident Remediation
- Exhibit I: Data Protection and Cybersecurity - Data Access/Storage Consent
- Exhibit J: Quality Assurance - Documentation and Handover Processes
- Exhibit K: Change Management - Timeline and Cost Adjustments
- Exhibit L: Force Majeure - Mitigation and Recovery Obligations
- Exhibit M: Termination - Transition Assistance and Data Handling
