Illinois construction independent contractor agreement template
View and compare the Free version and the Pro version.
Help Center
Need to learn how to convert downloaded contract DOCX files to PDF or add electronic signatures? Please visit our Help Center for detailed guidance.
How Illinois construction independent contractor agreement Differ from Other States
-
Illinois law requires strict compliance with the Illinois Employee Classification Act, imposing penalties for misclassification that differ from many other states.
-
Illinois mandates unique disclosure requirements regarding worker status and rights, which are not universally required in other states.
-
The state enforces specific insurance and tax registration rules for contractors that may not be present in agreements governed by laws elsewhere.
Frequently Asked Questions (FAQ)
-
Q: Is a written independent contractor agreement required in Illinois?
A: While not always required by law, a written agreement is highly recommended to clarify roles and comply with state labor statutes.
-
Q: What penalties exist in Illinois for misclassifying workers as independent contractors?
A: Illinois imposes fines, back payments, and other penalties under the Illinois Employee Classification Act for misclassification.
-
Q: Do Illinois independent contractors need specific insurance?
A: Yes, contractors in Illinois may be required to carry liability insurance and, in some cases, register for workers’ compensation coverage.
HTML Code Preview
Illinois Construction Independent Contractor Agreement
This Illinois Construction Independent Contractor Agreement (the “Agreement”) is made and entered into as of this [Date], by and between:
[Client Name], a [Client Entity Type], with a business address at [Client Address] (“Client”),
and
[Contractor Name], a [Contractor Entity Type], with a business address at [Contractor Address] (“Contractor”). Illinois Registration Details: [Contractor Registration Details, if applicable].
1. Project Description
The Client desires to engage the Contractor to perform certain construction services. The Contractor agrees to perform the services as described herein.
Option A: Detailed Description of Services: [Detailed Description of Construction Services, e.g., Carpentry, Electrical, Plumbing, etc.].
Option B: Scope of Work: The Contractor shall perform all work as described in Exhibit A, attached hereto and incorporated by reference, including specifications, blueprints, and applicable standards.
Option C: Project Site Address: The project site is located at [Project Site Address].
Option D: Applicable Standards/Building Codes: Illinois State Building Code, and if applicable, Chicago Building Code.
2. Scope of Work and Deliverables
The Contractor shall perform all work necessary to complete the project in accordance with the highest standards of the construction industry in Illinois.
Option A: Deliverables: The Contractor shall provide the following deliverables: [List of Deliverables].
Option B: Completion Criteria: The project shall be considered complete upon [Detailed Completion Criteria].
Option C: Milestones: The project shall be completed according to the following milestones: [List of Milestones].
Option D: Required Inspections: The Contractor is responsible for scheduling and passing all required inspections as per Illinois and local regulations.
3. Project Schedule
The Contractor shall commence work on [Commencement Date] and shall diligently pursue completion of the project by [Expected Completion Date].
Option A: Working Hours: Working hours are restricted to [Working Hours Restrictions] in accordance with local noise ordinances.
Option B: Extensions/Delays: Extensions or delays due to weather or force majeure shall be documented and submitted to the Client in writing for approval, in accordance with Illinois lien rights and waiver timing.
Option C: Critical Milestones: Failure to meet critical milestones as outlined in Section 2 may constitute a breach of this Agreement.
4. Materials, Equipment, and Labor
The Contractor is solely responsible for providing all labor necessary to complete the project.
Option A: Contractor-Supplied Materials/Equipment: The Contractor shall supply the following materials and equipment: [List of Materials and Equipment Contractor Provides].
Option B: Client-Supplied Materials/Equipment: The Client shall supply the following materials and equipment: [List of Materials and Equipment Client Provides].
Option C: Compliance: The Contractor shall comply with all applicable Illinois OSHA and workplace safety regulations.
5. Payment Terms
The Client shall compensate the Contractor as follows:
Option A: Lump-Sum Fee: The total compensation for the project is [Total Compensation Amount].
Option B: Cost-Plus Fee: The Contractor shall be compensated for the cost of materials plus a fee of [Percentage or Fixed Amount].
Option C: Unit Price: The Contractor shall be paid [Amount] per [Unit, e.g., square foot, linear foot].
Option D: Hourly Rate: The Contractor shall be paid [Hourly Rate] per hour.
Progress Payment Structure: Progress payments shall be made according to the following schedule: [Detailed Progress Payment Schedule].
Retainage: Retainage shall be withheld at a rate of [Retainage Percentage], not to exceed 10% until the project is 50% complete, then capped at 5% as per Illinois law.
Invoicing Schedule: The Contractor shall submit invoices to the Client on a [Invoicing Schedule, e.g., weekly, bi-weekly, monthly] basis.
Acceptance Requirements: Payment is contingent upon acceptance of completed work by the Client.
Reimbursement: The Contractor will be reimbursed for [Specific Reimbursable Expenses].
6. Taxes and Insurance
The Contractor acknowledges and agrees that they are solely responsible for all self-employment taxes, workers’ compensation (with relevant Illinois exemptions if solo contractor), local business taxes, and state tax registration obligations.
Option A: Insurance: The Contractor shall maintain the following insurance coverage:
Illinois minimum liability insurance of [Amount].
Property damage insurance of [Amount].
Auto insurance, if relevant, of [Amount].
Workers’ compensation coverage as required by Illinois law.
Option B: Certificates of Insurance: The Contractor shall provide certificates of insurance naming the Client as additionally insured.
7. Permits and Licenses
The Contractor is responsible for obtaining and paying for all permits and licenses necessary to comply with Illinois and local construction laws.
Option A: Publicly Funded Projects: If this contract is publicly funded, the Contractor shall comply with all applicable prevailing wage requirements.
8. Change Orders
Any changes to the scope of work must be documented in a written change order, signed by both the Client and the Contractor.
Option A: Change Order Process: The change order process shall include request, approval, pricing, documentation, and dispute handling, in accordance with Illinois change order laws.
9. Lien Waivers
The Contractor shall provide partial and final lien waivers from themselves and all subcontractors/material suppliers, in coordination with the Illinois Mechanics Lien Act.
Option A: Notification Procedures: The Contractor shall provide notification procedures for nonpayment or disputes.
10. Waste Disposal and Hazardous Materials
The Contractor shall be responsible for waste disposal, hazardous material handling, and cleanup standards in accordance with Illinois EPA and municipal regulations.
11. Subcontracting and Assignment
The Contractor shall not assign or subcontract any portion of the work without the prior written consent of the Client.
Option A: Subcontractor Identification: The Contractor shall identify any known subcontractors and provide documentation of their legal compliance and insurance coverage.
12. Warranty
The Contractor warrants that all workmanship and materials shall be free from defects for a period of [Warranty Duration, e.g., 1 year] from the date of completion.
Option A: Remedying Defects: The Contractor shall be responsible for remedying any defects during the warranty period in accordance with Illinois law.
13. Confidentiality
The Contractor shall maintain the confidentiality of all Client information, blueprints, and security measures.
14. Indemnification
The Contractor shall indemnify and hold harmless the Client from any claims, damages, liens, injuries, or regulatory penalties arising from the Contractor's actions or inactions, subject to Illinois anti-indemnity statute limitations (ensuring indemnity does not cover client’s own sole negligence).
15. Default and Termination
If either party breaches this Agreement, the non-breaching party shall have the right to terminate the Agreement upon written notice.
Option A: Termination for Cause: Termination for cause shall include specific remediation, cure periods, termination for cause or convenience, and mandatory return/handover of work and materials upon termination.
16. Final Inspection and Acceptance
Upon completion of the project, the Client shall conduct a final inspection and create a punch list of any remaining items to be completed.
Option A: Punch List Completion: The Contractor shall complete the punch list within [Time Frame] days of receipt.
17. Dispute Resolution
Any disputes arising out of this Agreement shall be resolved through negotiation, mediation, and, if necessary, litigation or arbitration in Illinois (venue and jurisdiction). Illinois law shall apply.
18. Compliance with Laws
The Contractor shall comply with all relevant local, state, and federal construction laws, licensing, codes, safety standards, wage laws, and anti-discrimination statutes.
19. Entire Agreement
This Agreement constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, whether written or oral.
20. Amendment
This Agreement may be amended only by a written instrument signed by both parties.
21. Severability
If any provision of this Agreement is held to be invalid or unenforceable, the remaining provisions shall remain in full force and effect.
22. Notices
All notices under this Agreement shall be in writing and delivered by [Required Form and Method, e.g., certified mail, electronic] to the addresses set forth above.
IN WITNESS WHEREOF, the parties have executed this Agreement as of the date first written above.
[Client Name]
By: [Client Signature]
Name: [Client Printed Name]
Title: [Client Title]
[Contractor Name]
By: [Contractor Signature]
Name: [Contractor Printed Name]
Title: [Contractor Title]
